Cal. PCC § 7102

This is the official text of Cal. PCC § 7102, part of California’s Public Contract Code — governs how California government agencies award and manage contracts.

Not legal advice. This page reproduces the official text of a government statute for reference only. Laws change, and how a statute applies depends on your specific facts. For advice about your situation, consult a licensed attorney in your state.

Official statutory text

Contract provisions in construction contracts of public agencies and subcontracts thereunder which limit the contractee’s liability to an extension of time for delay for which the contractee is responsible and which delay is unreasonable under the circumstances involved, and not within the contemplation of the parties, shall not be construed to preclude the recovery of damages by the contractor or subcontractor.

No public agency may require the waiver, alteration, or limitation of the applicability of this section. Any such waiver, alteration, or limitation is void. This section shall not be construed to void any provision in a construction contract which requires notice of delays, provides for arbitration or other procedure for settlement, or provides for liquidated damages.

Status: in_force · Read it on the official government site

Need a lawyer in California?

Find a California lawyer

About this page: Statute text is reproduced from official government publishers via the Open US Law dataset (Vaquill AI, snapshot v2026.08, CC BY 4.0). Primary legislative text like this is public domain under the government-edicts doctrine (Georgia v. Public.Resource.Org, 2020). We link every section back to its official source so you can verify it independently.