Mont. Code Ann. § 18-2-432
This is the official text of Mont. Code Ann. § 18-2-432, part of Montana’s Code Ann — part of the compiled statutory law of Montana, published by the state as "Code Ann." Browse the sections below, each linked to its official government source.
Not legal advice. This page reproduces the official text of a government statute for reference only. Laws change, and how a statute applies depends on your specific facts. For advice about your situation, consult a licensed attorney in your state.
18-2-432 Penalty for violation
Official statutory text
18-2-432 . Penalty for violation. (1) (a) If a person, firm, or corporation fails to comply with the provisions of this part, the state, county, municipality, school district, or officer of a political subdivision that executed the public works contract shall retain $1,000 of the contract price as liquidated damages for the violation of the terms of the public works contract, and the money must be credited to the proper funds of the state, county, municipality, school district, or political subdivision.
(b) If a person, firm, or corporation fails to comply with the provisions of this part due to gross negligence, as determined by the commissioner, the commissioner may retain up to an additional $10,000 above the amount provided for in subsection (1)(a) as a penalty for the violation of the terms of the public works contract. The money retained pursuant to this subsection (1)(b) must be credited to the proper funds of the state, county, municipality, school district, or other political subdivision.
(2) Whenever a contractor or subcontractor is found by the commissioner to have aggravatedly or willfully violated the labor standards provisions of this chapter, the contractor or subcontractor or any firm, corporation, partnership, or association in which the contractor or subcontractor has a substantial interest is ineligible, for a period not to exceed 3 years after the date of the final judgment, to receive any public works contracts or subcontracts that are subject to the provisions of this chapter.
(3) Whenever an action has been instituted in a district court in this state against any person, firm, or corporation for the violation of this part, the court in which the action is pending is authorized to issue an injunction to restrain the person, firm, or corporation from proceeding with a public works contract with the state, county, municipality, school district, or political subdivision, pending the final determination of the instituted action.
(b) If a person, firm, or corporation fails to comply with the provisions of this part due to gross negligence, as determined by the commissioner, the commissioner may retain up to an additional $10,000 above the amount provided for in subsection (1)(a) as a penalty for the violation of the terms of the public works contract. The money retained pursuant to this subsection (1)(b) must be credited to the proper funds of the state, county, municipality, school district, or other political subdivision.
(2) Whenever a contractor or subcontractor is found by the commissioner to have aggravatedly or willfully violated the labor standards provisions of this chapter, the contractor or subcontractor or any firm, corporation, partnership, or association in which the contractor or subcontractor has a substantial interest is ineligible, for a period not to exceed 3 years after the date of the final judgment, to receive any public works contracts or subcontracts that are subject to the provisions of this chapter.
(3) Whenever an action has been instituted in a district court in this state against any person, firm, or corporation for the violation of this part, the court in which the action is pending is authorized to issue an injunction to restrain the person, firm, or corporation from proceeding with a public works contract with the state, county, municipality, school district, or political subdivision, pending the final determination of the instituted action.
Status: in_force · Read it on the official government site
Need a lawyer in Montana?
Find a Montana lawyer
About this page: Statute text is reproduced from official government publishers via the
Open US Law dataset
(Vaquill AI, snapshot v2026.08, CC BY 4.0). Primary legislative text like this is public domain under the government-edicts doctrine
(Georgia v. Public.Resource.Org, 2020). We link every section back to its official source so you can verify it independently.