Nev. Rev. Stat. § 108.2453
This is the official text of Nev. Rev. Stat. § 108.2453, part of Nevada’s Rev. Stat — part of the compiled statutory law of Nevada, published by the state as "Rev. Stat." Browse the sections below, each linked to its official government source.
Not legal advice. This page reproduces the official text of a government statute for reference only. Laws change, and how a statute applies depends on your specific facts. For advice about your situation, consult a licensed attorney in your state.
Waiver or modification of right, obligation or liability set forth in NRS 108.221 to 108.246, inclusive, prohibited; certain conditions, stipulations or provisions of contract for improvement of property or construction, alteration or repair of work of im
Official statutory text
1. Except as otherwise provided in NRS 108.221 to 108.246 , inclusive, a person may not waive or modify a right, obligation or liability set forth in the provisions of NRS 108.221 to 108.246 , inclusive.
2. A condition, stipulation or provision in a contract or other agreement for the improvement of property or for the construction, alteration or repair of a work of improvement in this State that attempts to do any of the following is contrary to public policy and is void and unenforceable: (a) Require a lien claimant to waive rights provided by law to lien claimants or to limit the rights provided to lien claimants, other than as expressly provided in NRS 108.221 to 108.246 , inclusive; (b) Relieve a person of an obligation or liability imposed by the provisions of NRS 108.221 to 108.246 , inclusive; (c) Make the contract or other agreement subject to the laws of a state other than this State; (d) Require any litigation, arbitration or other process for dispute resolution on disputes arising out of the contract or other agreement to occur in a state other than this State; or (e) Require a prime contractor or subcontractor to waive, release or extinguish a claim or right that the prime contractor or subcontractor may otherwise possess or acquire for delay, acceleration, disruption or impact damages or an extension of time for delays incurred, for any delay, acceleration, disruption or impact event which was unreasonable under the circumstances, not within the contemplation of the parties at the time the contract was entered into, or for which the prime contractor or subcontractor is not responsible.
2. A condition, stipulation or provision in a contract or other agreement for the improvement of property or for the construction, alteration or repair of a work of improvement in this State that attempts to do any of the following is contrary to public policy and is void and unenforceable: (a) Require a lien claimant to waive rights provided by law to lien claimants or to limit the rights provided to lien claimants, other than as expressly provided in NRS 108.221 to 108.246 , inclusive; (b) Relieve a person of an obligation or liability imposed by the provisions of NRS 108.221 to 108.246 , inclusive; (c) Make the contract or other agreement subject to the laws of a state other than this State; (d) Require any litigation, arbitration or other process for dispute resolution on disputes arising out of the contract or other agreement to occur in a state other than this State; or (e) Require a prime contractor or subcontractor to waive, release or extinguish a claim or right that the prime contractor or subcontractor may otherwise possess or acquire for delay, acceleration, disruption or impact damages or an extension of time for delays incurred, for any delay, acceleration, disruption or impact event which was unreasonable under the circumstances, not within the contemplation of the parties at the time the contract was entered into, or for which the prime contractor or subcontractor is not responsible.
Status: in_force · Read it on the official government site
Need a lawyer in Nevada?
Find a Nevada lawyer
About this page: Statute text is reproduced from official government publishers via the
Open US Law dataset
(Vaquill AI, snapshot v2026.08, CC BY 4.0). Primary legislative text like this is public domain under the government-edicts doctrine
(Georgia v. Public.Resource.Org, 2020). We link every section back to its official source so you can verify it independently.