Tex. Transportation Code § 315.094
This is the official text of Tex. Transportation Code § 315.094, part of Texas’s Transportation Code — governs vehicles, drivers, and roadways.
Not legal advice. This page reproduces the official text of a government statute for reference only. Laws change, and how a statute applies depends on your specific facts. For advice about your situation, consult a licensed attorney in your state.
§ 315.094. AFFIDAVIT.
Official statutory text
(a) In a suit brought under Section 315.092, an affidavit must be attached to the plaintiff's petition stating:
(1) that the matters alleged in the petition are true, except for matters alleged on information and belief; and
(2) that the suit is brought in good faith and not to injure or delay the municipality, the contractor, or an owner of abutting property.
(b) If the plaintiff does not attach the affidavit required by this section, the court shall dismiss the suit on a defendant's motion and the plaintiff is barred to the same extent as if suit had not been brought.
(1) that the matters alleged in the petition are true, except for matters alleged on information and belief; and
(2) that the suit is brought in good faith and not to injure or delay the municipality, the contractor, or an owner of abutting property.
(b) If the plaintiff does not attach the affidavit required by this section, the court shall dismiss the suit on a defendant's motion and the plaintiff is barred to the same extent as if suit had not been brought.
Status: in_force · Read it on the official government site
Need a lawyer in Texas?
Find a Texas lawyer
About this page: Statute text is reproduced from official government publishers via the
Open US Law dataset
(Vaquill AI, snapshot v2026.08, CC BY 4.0). Primary legislative text like this is public domain under the government-edicts doctrine
(Georgia v. Public.Resource.Org, 2020). We link every section back to its official source so you can verify it independently.